Jobs

Qualified LBP Carpenter

RegionAuckland

⭐️HIRING⭐️ - Do you want a great job where you earn top dollar and love coming to work

Are you keen to not only develop your practical knowledge and skills, but also take on new & exciting challenges.

WE CAN OFFER

Top rates depending on your skills, qualifications and experience

A paid day off for your birthday

A boss and team that look after you

Ongoing mentoring from the company owners

The ability to step up & run jobs Key qualities we are looking for in our employees-

Qualified LBP Carpenter

Clean Drivers Licence

Able to work unsupervised & solve problems

Honest and trustworthy

Show initiative to complete tasks to the highest standard & within timeframes

Great people skills to work alongside team mates & customers So. If you think you fit the job and would be an asset to our amazing team at MBD Builders then we would love to hear from you! Apply now by sending your CV and a brief cover letter telling us about you and why you would suit this role mailto:[email protected] 021-665646

Euan Smith

021-665646

Email hidden; Javascript is required.

ListedOctober 24, 2021

Builder

RegionManawatu-Wanganui

Experienced builders wanted

• New builds

• Competitive salary

• Weekly pay

We are looking for experienced Builders who are competent & capable of building new homes to a high standard, within a timely manner.

Must be able to work unsupervised, and willing to supervise others including apprentices and hammer hands when required.

Must be able to communicate with team members and suppliers. Must have own tools and reliable vehicle (possible work vehicle for the right candidate).

We are a quickly growing team with work across the lower north island.

Jack Mitchell

02040004045

Email hidden; Javascript is required.

ListedOctober 21, 2021

Foreman role available in the sunny Bay of Plenty!

RegionBay of Plenty

Qualified Builder

We are a local commercial and residential Construction company with a long-standing reputation in the Rotorua and wider Bay of Plenty Region for superior craftsmanship. Our business does it all – from new builds, renovations, smaller projects and large commercial projects. Our team work alongside our clients from the very beginning to the very end offering a personal level of service throughout the journey.

An exciting opportunity for an experienced and fully qualified and licensed (LBP) Builder is now up for the taking to join our amazing team.

This role will encompass all day-to-day construction for our various residential and commercial projects. You will also assist in leading and developing apprentices on site, so experience in training apprentices and leadership experience is a distinct advantage!

About you:

Fully trade qualified and hold LBP (Licensed Building Practitioner - preferred)

A minimum of 5 years + post apprenticeship building experience

Experience guiding and supervising small teams

Commercial and residential building experience

Strong communication skills

Ability to work cohesively in a small team and lead from the front

Organised, strong attention to detail, taking pride in your work is key

Experienced in Health & Safety Management for construction sites an advantage

What can you expect from us:

Company vehicle

Brand new workplace offices

Company uniform, PPE

Tool allowance and more

But most of all – due to the size of our business, we are flexible and we look after our people. Our clients know us to take time to listen and provide valuable advice and support throughout the build process, and this is the same for our team members. We are a family owned business and proud of our values and our team are part of that family.

If you want a change, working in a smaller team, better conditions, great group of people, great benefits then get in touch with us today.

Please forward your resume and covering letter to:

Maree Judd

M Judd Consulting Ltd

E: [email protected]

Maree Judd

Email hidden; Javascript is required.

ListedOctober 20, 2021

Carpenter/builder

RegionAuckland

Description

We are currently seeking a qualified Commercial Builder/experience If you are keen to work in a team and enjoying working with a great company, then this role is for you.

What we offer:

Excellent pay ratesFull time workWorking for a well-established NZ owned companyWeekly pay

What we need from you:

Ability to read construction plans and drawingsAbility to work with no supervisionGood communication skillsOrganisation skillsMotivated and reliableA great attitude

Apply below Applicants for this position should have NZ residency or a valid NZ work visa

Gavin

021507615

Email hidden; Javascript is required.

ListedOctober 20, 2021

2nd or 3rd year apprectice

RegionAuckland

We are looking for a second or 3rd-year apprentice to join our team of highly skilled tradesmen. We do high end architectural homes and renovations mainly in the eastern suburbs.

Must be a non smoker but open to discussion on tools, rates etc.

Cary Gleeson

0274729840

Email hidden; Javascript is required.

ListedOctober 18, 2021

Hiring now - Wanaka!

RegionOtago

CBG Quality Construction are on the hunt for L.B.P’s and Carpenters to join us on our journey to crafting energy-efficient, healthy homes that reflect our stunning environment and stand the test of time well into the future.

Do you want a job with passion and purpose, where you have the opportunity to build high performing homes?

Do you want a great place to work where you are valued and have plenty of scope to learn and implement your ideas within the company?

Do you have a passion for the outdoors?

This role could be perfect for you if you have what it takes.

Please read the following and only apply if you meet the requirements

What we offer:

High quality, high performance work
Great pay rates depending on skills, qualifications and experience
A slick uniform
A boss and team that looks after each other and works together
Company culture - we enjoy what we do, and we are a family
The opportunity to learn and elevate yourself

About the role:

We require a self -motivated individual who can read drawings and specifications and carry out the works accordingly .The ideal person must have a high work standard in all facets of carpentry from formwork to finishing . Previous experience in high end housing is essential . You must be a problem solving individual with a can do attitude and can relate to all contractors and suppliers.

Must have national cert in carpentry
LBP preferred (But not essential)
You are looking to continually upskill and learn
Excellent communicator with a good attitude
Strong leadership skills
Tidy, organised and punctual
Excellent level of fitness and health
Own tools
A NZ Drivers License
Own reliable transport
Experience with SIP Panels is preferred but not essential
NZ Work Visa

Please email your current resume and a covering letter [email protected] or call Clint to discuss on 0272261284

Find out more

Clint

0272261284

Email hidden; Javascript is required.

CBG_SIPLogo_colour-transparent.pdf

ListedOctober 6, 2021

Office Administrator

RegionBay of Plenty

We are looking for a new Office Administrator superstar to join our team. We are locally owned business in the construction and building industry, where you will be providing administrative support to the owner. This is a role that you can stamp your mark and make your own.

We are offering:

Flexible, mostly autonomous hours, working approx. 10 - 15 hours a week

Great hourly rate

Interesting and varied role within the construction industry

We are looking for:

Self-driven office all-rounder, flexible and well organised

Awesome verbal and written communication and customer service skills

Preparation of customer quotes and Building Contracts

Proficient in MS Office

Knowledge of BuildaPrice, Rave Project Management and Xero desirable

Basic marketing experience using Canva and Mailchimp

Find out more

Rob Bullock

021 044 6505

Email hidden; Javascript is required.

ListedMay 14, 2021

Foreman / Carpenter

RegionBay of Plenty

Qualified Carpenter required to join our team of six!

Construction 41 is a dynamic and growing company in Tauranga who look after and respect our employees. We currently have more work coming in than we can handle and require a new team member. Could you be what we are looing for?

Are you qualified, LBP, have a full kit of tools?
Are you able to work unsupervised and problem solve?
Are you honest & trustworthy?
Have great people skills to work alongside team mates and clients?

If you think you fit the profile and would be an asset to our team at Construction 41 then APPLY NOW via email with your CV and a brief cover letter. [email protected]. If you have a question about the role please call Rob on 012 044 6505

Find out more

Rob Bullock

021 044 6505

Email hidden; Javascript is required.

ListedMarch 10, 2021

Qualified Carpenters & Hammerhands Wanted

RegionAuckland

Successful candidates will be on the tools and able to work unsupervised.

Ideally you will have:

- Minimum 4 years building experience
- A strong work ethic with excellent time management skills.
- The ability to work well in a team environment, with a focus on quality workmanship, attention to detail and health and safety.
- Willing to travel within Auckland City.
- Own transport/full “clean” license
- Full set of tools
- References
- Communication is essential with co-workers and clients and therefore you must have an excellent level of English.
- Applicants for this position should have NZ residency or a valid NZ work visa.

If you feel you could meet the above criteria and would like to join our team, we would be keen to meet you.

Find out more

Nick Lowe

021831311

Email hidden; Javascript is required.

ListedMarch 4, 2021

Apprentices required

RegionAuckland

We are on the look out for new apprentices to join our team. We can offer a variety of work, And can provide help towards Purchasing of tools. We do town houses ,stand alone houses and Architectural designs. Saturday work is available is you require. Multiple sites around Auckland so a reliable vehicle would be a Must.

Contact Jeremy Cox

Construction Manager

0272515726

or by email [email protected]

Find out more

Jeremy Cox

0272515726

Email hidden; Javascript is required.

ListedAugust 20, 2020

handson Foreman/Forewoman

RegionWellington

Able Spaces custom builds to order transportable homes and supplies them throughout NZ. With the goals we want to accomplish this year, we are looking for an awesome hands on foreperson. We're based in Stokes Vegas (Stokes Valley, Lower Hutt), so this is a good opportunity to avoid traffic (nobody's got time for that!).

We're a team of 9 and need an extra pair of hands to work side by side and lead the way for our 3 first year BCITO apprentices in constructing our transportable homes and commercial portable buildings. We also have 2 labourers who help out with a variety of stuff around the workshop.

We're looking for someone qualified with residential construction experience with a sense of humour, who can get the most out of our team and get our homes looking stunning on time and on budget!

You need to be able to:

lead by example

communicate in a way the team understand what they need to do, how and why

bring some banter and make sure the team is having fun while working (life's too short not to!)

work closely with the Manufacturing Manager and office staff to ensure our ship sails smoothly

We build with Metalcraft Structurally Insulated Panels so experience with those would be ideal but not necessary. We use a variety of cladding and internal linings and each house is different to the previous one. It's not rocket science though and we like to keep things simple yet provide a unique product to our customers.

The job also includes the following responsibilities:

Identify how we can make our homes better

Identify how we can build our buildings more effectively

Running Toolbox talks and daily start ups to ensure everyone is safe and productive

We're continually creating new layouts, looking out for new cladding and lining options, how we can improve our product and we're currently designing 2 storeys. Just because our homes are built under a roof don't think for a second that everything is just the same and boring. Far from it.

So if you're looking for a new challenge and want to join an awesome team where we value having fun at work, honesty, integrity and being straight up, call or email us!

PLEASE do not apply if you do not have experience in residential building.

Applicants for this position should have NZ residency or a valid NZ work visa. Please contact us for the job description.

Find out more

Norma McCarty

021549923

Email hidden; Javascript is required.

ListedJanuary 22, 2020

12.1	Part G of the Schedule contemplates that the Parties will elect who is responsible for arranging the contract works insurance. If the Parties have not made that election or if their intention is unclear, then the Owner must arrange contract works insurance if the Building Work involves changes, alterations, renovations, restoration, repairs or maintenance to existing structures, and the Builder is responsible for arranging contract works insurance if the Building Work involves constructing an entirely new stand-alone structure. Irrespective of who arranges the contract works insurance, the excess on a contract works claim is payable by the Owner. Given that such insurance typically expires on Practical Completion, the Owner must ensure that the Building is insured from that point onwards.
12.2	The amount insured must be at least as much as the Original Contract Price, plus an allowance for Owner-supplied materials, expediting expenses, removal of debris, professional fees, increased costs during construction, increased costs during reconstruction, and materials in storage (off the Project site). Unless otherwise agreed, the allowances for these items shall be those shown in Part G of the Schedule, and if no allowance is made in that Part for any item then the allowance must be reasonable in the circumstances.
12.3	The Owner must arrange contract works insurance against loss or damage to the Owner’s existing structures made available by the Owner to enable the performance of the Building Work, or existing structures adjacent to the Building, and to the Owner’s contents. This insurance must be for the full replacement value, and for consequential loss arising from loss or damage to those structures and contents.
12.4	The Builder must arrange public liability insurance for loss or damage to any property, or illness, injury or death to any person, that arises from the performance of the Building Work.
12.5*	In the event of loss or damage to any part of the Building which is not caused by the Builder or any party for whom the Builder is responsible:
	a.	The Builder is not required to carry out any restoration work at the Builder’s own expense.
	b.	The Builder will restore all loss or damage to the Building and the restoration work will be treated as a Variation.
	c.	The restoration work will be paid for from the proceeds of the contract works insurance.
	d.	If the delay in confirming insurance cover after loss or damage to the Building has occurred is such that the Builder can no longer reasonably afford to maintain spare capacity to perform the Building Work when required, the Builder may suspend the Building Work as if clause 20.2 applied, and if the Builder has not cancelled the contract in the meantime, the Builder shall not be obliged to resume the Building Work until the Builder’s commitments reasonably allow for a resumption.
12.6	If this Contract is completed on-line, and either Party has selected the option to apply for a contract works policy marketed under the “REDi” brand, then an application for such a policy will be automatically generated from the information entered into the Schedule of this Contract.
12.7	The insurance broker responsible for arranging the REDi contract works policy and the underwriter(s) to whom the application is submitted together with their respective representatives or agents are authorised to obtain from, and disclose to, any other party any information they consider relevant to the assessment of the application for the policy.
12.8	For the purpose of section 12 of the Contract and Commercial Law Act 2017, the provisions in this Part 12 are intended to create obligations enforceable by the insurance broker and the underwriter(s) referred to in clause 12.7 and their respective representatives or agents, whether or not they are parties to this Building Contract.

4.1	This is a building contract in which the total price payable for the Building Work is not fixed, specified, or known at the time of entering into the Contract. Instead, the progress payments and the Final Contract Price are to be calculated by reference to the actual costs incurred by the Builder in carrying out the Building Work, plus a Margin for the Builder’s Off-site Overheads and profit. The Parties may have chosen to enter into this form of building contract for any number of reasons, including that it is too difficult for the Builder and/or the Owner to accurately predict the precise scope of the Building Work at the outset, or the Building Work involves innovative systems or materials the cost of which is largely unknown, or to avoid the administrative burden of having to recalculate a fixed contract price each time a component of the work changes, or simply because it is their preference to do so. While this inevitably involves some uncertainty as to what the Final Contract Price will eventually amount to, it has the advantage that at the conclusion of the Building Work the Owner will have become liable to pay no more and no less than the value of the Building Work and materials the Owner has actually received.
4.2	The progress payments and the Final Contract Price payable to the Builder shall therefore be calculated by reference to the hours of work expended by the Builder and the Builder’s employees and contractors in carrying out the Building Work, plus the materials and other direct costs incurred by the Builder in carrying out the Building Work, using the rates set out in Part F of the Schedule. Onto those amounts shall then be added the Margins for the Builder’s Off-site Overheads and profit, calculated by reference to the percentages shown in Part F of the Schedule.
4.3	The Builder shall be entitled to charge for and recover all costs that the Builder would not have incurred but for the Building Work, and that are reasonably necessary to carry out the Building Work to the standard required by this Contract, plus the relevant Builder’s Margins. Those costs include (without limitation):
	a.	The Builder’s own labour and labour performed by the Builder’s employees and contractors.
	b.	Products or services from subcontractors or specialist trades.
	c.	Professional advice such as architecture and engineering.
	d.	Building materials and consumables.
	e.	Hireage of tools, plant, equipment, appliances or vehicles.
4.4	The cost of labour shall be calculated using the labour rates set out in Part F of the Schedule, or where no rates have been specified in any particular case, at the prevailing market rates for the personnel in question. The labour rates set out in Part F of the Schedule apply to normal working hours and days, and in calculating working hours no deduction shall be made for work breaks that are reasonably necessary for the consumption of food or beverages or to ensure the continued health, safety, productivity and efficiency of the relevant personnel. Where in order to comply with the Builder’s obligations under this Contract it is reasonably necessary for the Builder and/or the Builder’s employees and subcontractors to carry out Building Work outside of normal working hours or on weekends or public holidays, and the Builder is required to pay penal or overtime rates as a result, those penal or overtime rates shall be included in the calculation of the cost of the Building Work.
4.5	All the costs of the Building Work apart from labour shall be calculated by reference to the invoice issued to the Builder for the relevant item, or if no invoice was issued, by reference to what the Builder actually paid. Where such costs cannot be separately identified or accurately ascertained through timesheets, invoices or otherwise, the cost of those items shall be calculated having regard to the prevailing market price for the relevant items.
4.6	The rates set out in Part F of the Schedule shall be adjusted for any increase in the rates charged by subcontractors that could not reasonably have been foreseen by the Builder at the time this Contract is signed by the Builder, and which would otherwise have the effect of eroding the Builder’s profit margin. The Builder must be able to substantiate the increase by reference to written evidence such as quotations, communications or invoices from the relevant subcontractor, clearly demonstrating the rates that were first advised to the Builder when Part F of the Schedule was completed, and the rates subsequently charged. The Builder shall whenever reasonably practicable, resist any rate increases and procure subcontracts on the basis of fixed rates that cannot be increased during the course of the Building Work.
4.7	If any of the subcontractor rates set out in Part F of the Schedule decrease for any reason (other than rebates or discounts provided to the Builder as a result of such factors as loyalty, volume of business, enticement to form a new or long term trading relationship, or membership of a trade association or cooperative company), the decreased rate(s) shall be used in the calculation of all progress payments and the Final Contract Price from the time that the decrease takes effect.
4.8	Either prior or subsequent to the Parties entering into this Contract, the Builder may have given or may give to the Owner or the Owner’s representative(s) an estimate, indication, projection, guess, intimation, prediction or similar communication (together referred to as an “estimate”) as to what the Final Contract Price or any component of it is likely to turn out to be. It is common for building owners to request an estimate and it is common for builders, in good faith and out of a desire to be helpful, to comply with that request, or indeed to offer an estimate unsolicited. The Parties acknowledge that even the most carefully calculated estimate can in hindsight prove to be grossly pessimistic or optimistic, and it is impossible for the Builder to accurately predict what the final outcome of the Project will be, given that so many factors are outside the Builder’s control.
4.9	The Parties have chosen this form of contract rather than a fixed price contract because they have agreed that the Final Contract Price will be determined by the hours of work and the materials and other direct costs that are ultimately involved, and the margin applied to those items. By definition, those hours and those costs cannot be known in advance. The Parties therefore expressly record that any such estimate that may have been or may be provided by the Builder – assuming the Builder used the term “estimate” or some reasonably equivalent expression – shall only represent the Builder’s best guess, based on the Builder’s experience and what the Builder knows about the Project itself to date. The Builder agrees to take reasonable care in calculating any estimate that may be given, and to keep the Owner regularly informed, by the provision of periodic invoices or otherwise, of the amount paid and payable to the Builder in respect of the Building Work at any given time.
4.10	A price estimate is fundamentally different from an undertaking, promise, commitment, statement, assurance, warranty or representation (together referred to as a “representation”) that the total contract price will amount to, or will not exceed, a stated or fixed sum. If the Builder has given such a representation, then that will bind the Builder in accordance with its terms. However the representation must be reasonably inferred from the wording used. For example if either of the Parties has, without full knowledge of the legal significance, mistakenly described an estimate as a “quote” or used some other wording that might suggest a representation that would be enforceable in law, then that will not constitute a representation if the Parties did not intend it to have that effect.

13.1	Part H of the Schedule contemplates that the Parties will elect who is responsible for arranging the contract works insurance. If the Parties have not made that election or if their intention is unclear, then the Owner must arrange contract works insurance if the Building Work involves changes, alterations, renovations, restoration, repairs or maintenance to existing structures, and the Builder is responsible for arranging contract works insurance if the Building Work involves constructing an entirely new stand-alone structure. Irrespective of who arranges the contract works insurance, the excess on a contract works claim is payable by the Owner. Given that such insurance typically expires on Practical Completion, the Owner must ensure that the Building is insured from that point onwards.
13.2	The amount insured must be at least as much as the Original Contract Price, plus an allowance for Owner-supplied materials, expediting expenses, removal of debris, professional fees, increased costs during construction, increased costs during reconstruction, and materials in storage (off the Project site). Unless otherwise agreed, the allowances for these items shall be those shown in Part H of the Schedule, and if no allowance is made in that Part for any item then the allowance must be reasonable in the circumstances.
13.3	The Owner must arrange contract works insurance against loss or damage to the Owner’s existing structures made available by the Owner to enable the performance of the Building Work, or existing structures adjacent to the Building, and to the Owner’s contents. This insurance must be for the full replacement value, and for consequential loss arising from loss or damage to those structures and contents.
13.4	The Builder must arrange public liability insurance for loss or damage to any property, or illness, injury or death to any person, that arises from the performance of the Building Work.
13.5	In the event of loss or damage to any part of the Building which is not caused by the Builder or any party for whom the Builder is responsible:
		a.	The Builder is not required to carry out any restoration work at the Builder’s own expense.
		b.	The Builder will restore all loss or damage to the Building and the restoration work will be treated as a Variation.
		c.	The restoration work will be paid for from the proceeds of the contract works insurance.
		d.	If the delay in confirming insurance cover after loss or damage to the Building has occurred is such that the Builder can no longer reasonably afford to maintain spare capacity to perform the Building Work when required, the Builder may suspend the Building Work as if clause 20.2 applied, and if the Builder has not cancelled the contract in the meantime, the Builder shall not be obliged to resume the Building Work until the Builder’s commitments reasonably allow for a resumption.
13.6	If this Contract is completed on-line, and either Party has selected the option to apply for a contract works policy marketed under the “REDi” brand, then an application for such a policy will be automatically generated from the information entered into the Schedule of this Contract.
13.7	The insurance broker responsible for arranging the REDi contract works policy and the underwriter(s) to whom the application is submitted together with their respective representatives or agents are authorised to obtain from, and disclose to, any other party any information they consider relevant to the assessment of the application for the policy.
13.8	For the purpose of section 12 of the Contract and Commercial Law Act 2017, the provisions in this Part 13 are intended to create obligations enforceable by the insurance broker and the underwriter(s) referred to in clause 13.7 and their respective representatives or agents, whether or not they are parties to this Building Contract.

9.1	The Builder shall commence the Building Work within a reasonable time after:
	a.	the Contract has been signed by both parties; and
	b.	any deposit payable in accordance with clause 7.2 has been paid; and
	c.	any necessary Building Consent or resource consent or other requisite consents or licences or consent amendments have been issued.
9.2	Unless otherwise agreed in writing between the Parties, the Owner shall obtain all project information memoranda, Building Consents, resource or other consents or licences, and consent amendments required for the Building Work.
9.3	The Owner shall promptly provide all information reasonably required by the Builder to enable the Builder to comply with the Builder’s obligations under this Contract, whether prior to the commencement of, during the performance of, or after the completion of the Building Work.
9.4	The expected completion date stated in Part B of the Schedule shall be automatically extended by a reasonable time where delays arise due to:
	a.	Variations;
	b.	Any strike, lockout, or other industrial action;
	c.	Loss or damage to the Building Work other than loss or damage caused by the Builder’s breach of its obligations under this Contract;
	d.	Flood, volcanic, or seismic events;
	e.	Inclement weather;
	f.	Failure to obtain consent or approval through no fault of the Builder;
	g.	Failure by the Owner to give timely directions;
	h.	Unforeseen physical conditions;
	i.	The Builder exercising its right to suspend the Building Work under this Contract;
	j.	Act, omission or default by the Owner or any person for whose acts or omissions the Owner is responsible;
	k.	A separate contractor’s act or omission;
	l.	Unavailability or shortage of materials;
	m.	Any other event which is beyond the reasonable control of the Builder and for which the Builder is not responsible.

7.1	The Builder is not obliged to commence the Building Work until any deposit payable in accordance with clause 7.2 has been paid.
7.2	The Deposit shall be paid by the Owner upon signing the Contract. The Deposit shall be held by the Builder and applied towards payment of the final invoice, or as provided by clause 20.9 or clause 21.4. The Deposit is therefore not to be treated as a progress payment. If the final invoice is less than the Deposit then the Builder shall pay the Owner the balance of the Deposit upon issuing the final invoice.
7.3	The Owner shall make progress payments to the Builder for Building Work completed and materials supplied, including any adjustments for Provisional Sums, cost fluctuations or Variations, up to the end of the applicable period or stage of work. The payments shall be made into a bank account provided by the Builder via internet banking or direct deposit, unless the parties agree on a different payment method.
7.4	Where the parties have agreed to progress payments at completion stages (Option A in Part E of the Schedule) the Builder may issue an invoice at any time after a relevant stage of completion is reached. If a completion stage cannot be reached due to matters beyond the Builder’s reasonable control, and one month has elapsed since the previous invoice, the Builder may invoice for the proportion of that completion stage that has been reached.
7.5	Where the parties have agreed to progress payments at the end of defined periods of time (Option B in Part E of the Schedule) the Builder may issue an invoice for the Building Work completed up to the end of each such period. Any invoice issued in advance of the end of the relevant period (other than a final invoice) shall be deemed to have been issued on the last working day of that period.
7.6	The Owner must pay the invoiced amount in full within 5 Working Days of the invoice being delivered or sent to the Owner or such other time as is stated in Part F of the Schedule. If the Owner does not consider that all or any part of the invoiced amount is payable, the Owner must, within 5 Working Days after the invoice was delivered or sent to the Owner:
	a.	reply in writing to the Builder stating the amount that the Owner considers payable (the undisputed amount), and
	b.	specifying the reasons why any part of the invoiced amount is disputed, and the method in which the disputed amount has been calculated; and
	c.	pay the undisputed amount.
7.7	If the Builder’s invoice is or is accompanied by a payment claim made under the CCA, then any payment schedule as defined in section 5 of that Act must be provided to the Builder within 5 Working Days of the payment claim being served on the Owner.
7.8	The Owner shall pay progress payments on the due dates, irrespective of when the Owner’s bank or financier is prepared to advance any monies required by the Owner in order to meet the Owner’s payment obligations under this Contract. It is the Owner’s responsibility to ensure that sufficient funds are available to comply with the Owner’s payment obligations under this Contract. The issue of a Code Compliance Certificate is not a prerequisite to Practical Completion or the Builder’s entitlement to payment of the final invoice.
7.9	The Owner may at any time request the Builder to provide a receipt or statement recording or evidencing the payments received from the Owner.
7.10	The Parties will comply with their obligations (if any) under Subpart 2A of the CCA (which requires certain retention monies to be held on trust or otherwise secured) to the extent that Subpart 2A applies to this Contract. The purpose of this provision is to ensure that an adjudicator appointed under the CCA or an arbitrator appointed under the Arbitration Act 1996 has jurisdiction to make a determination in respect of any such obligations, as if they were expressly incorporated into this Contract.

Jobs

Jobs

Qualified LBP Carpenter

RegionAuckland

Euan Smith

021-665646

Builder

RegionManawatu-Wanganui

Jack Mitchell

02040004045

Foreman role available in the sunny Bay of Plenty!

RegionBay of Plenty

Maree Judd

Carpenter/builder

RegionAuckland

Gavin

021507615

2nd or 3rd year apprectice

RegionAuckland

We are looking for a second or 3rd-year apprentice to join our team of highly skilled tradesmen. We do high end architectural homes and renovations mainly in the eastern suburbs. Must be a non smoker but open to discussion on tools, rates etc.

Cary Gleeson

0274729840

Hiring now - Wanaka!

RegionOtago

What we offer:

About the role:

Clint

0272261284

Office Administrator

RegionBay of Plenty

Rob Bullock

021 044 6505

Foreman / Carpenter

RegionBay of Plenty

Rob Bullock

021 044 6505

Qualified Carpenters & Hammerhands Wanted

RegionAuckland

Nick Lowe

021831311

Apprentices required

RegionAuckland

Jeremy Cox

0272515726

handson Foreman/Forewoman

RegionWellington

Norma McCarty

021549923

Being a NZCB member is good for business.

The website is undergoing maintenace, please come back later.

12 Insurance

4. Calculation of Progress Payments & Final Contract Price

13 Insurance

9. Commencement and Completion of Work

Make a technical enquiry

7 Invoices and payments

4 Calculation of Progress Payments & Final Contract Price

6. Invoices and Payments

8 Commencement and Completion of Work

USER INFO UPDATE REQUEST

We are looking for a second or 3rd-year apprentice to join our team of highly skilled tradesmen. We do high end architectural homes and renovations mainly in the eastern suburbs.

Must be a non smoker but open to discussion on tools, rates etc.